Abstract
The decision to use static, dynamic, additive, or subtractive delay analysis is critical because making the wrong decision may have serious undesired consequences. As a response to this problem, a delay analysis selection (DAS) model was developed that identifies the most appropriate type of delay analysis for a target case. The model constitutes the first step of a two-step process to perform delay analysis. It involves a case-base that is populated by 3,776 possible cases developed by using combinations of 26 attributes that were found in the literature to influence the selection of the most appropriate type of delay analysis. The 26 attributes were organized in 7 categories. The weights of the attributes and the categories were calculated using the entropy method. The DAS model finds the best match between a target case and one of the cases stored in the case-base by performing weighted case similarity assessment. The type of delay analysis that is indicated in the matched case is adopted for use in the target case. This study is the first attempt to automate the selection of the most appropriate type of delay analysis. Once the most suitable type of delay analysis is identified in the first step, it is immediately performed in the second step.
Similar content being viewed by others
References
Abdelhadi Y, Dulaimi MF, Bajracharya A (2019) Factors influencing the selection of delay analysis methods in construction projects in UAE. International Journal of Construction Management 19(4): 329–340, DOI: https://doi.org/10.1080/15623599.2018.1435155
Akogbe RKT, Feng X, Zhou J (2013) Importance and ranking evaluation of delay factors for development construction projects in Benin. KSCE Journal of Civil Engineering 17(6):1213–1222, DOI: https://doi.org/10.1007/s12205-013-0446-2
Alkass S, Mazerolle M, Harris F (1996) Construction delay analysis techniques. Construction Management & Economics 14(5):375–394, DOI: https://doi.org/10.1080/014461996373250
Arditi D, Pattanakitchamroon T (2006) Selecting a delay analysis method in resolving construction claims. International Journal of Project Management 24(2):145–155, DOI: https://doi.org/10.1016/j.ijproman.2005.08.005
Arditi D, Pattanakitchamroon T (2008) Analysis methods in time-based claims. Journal of Construction Engineering and Management 134(4):242–252, DOI: https://doi.org/10.1061/(ASCE)0733-9364(2008)134:4(242)
Armed Services Board of Contract Appeals (ASBCA) (2003) Contel Advanced Systems, Inc. No. 49074, Armed Services Board of Contract Appeals, Retrieved September 11, 2021, https://www.asbca.mil/Decisions/decisions2003.html
Asiedu RO, Alfen HW (2016) Understanding the underlying reasons behind time overruns of government building projects in Ghana. KSCE Journal of Civil Engineering 20(6):2103–2111, DOI: https://doi.org/10.1007/s12205-015-0544-4
Association for the Advancement of Cost Engineering International (AACEI) (2011) AACE International Recommended Practice 29R-03 Forensic schedule analysis. Association for the Advancement of Cost Engineering International, Morgantown, WV, USA, 9–131
Avalon A (2017) Choosing the most appropriate schedule analysis method. Long International, Retrieved August 9, 2021, https://www.long-intl.com/articles/schedule-analysis-method-2/
Baram GE (1994) Delay analysis-issues not for granted. AACE International Transactions, DCL5.1-DCL5.9
Baram GE (2000) The window methods of analyzing delay claims. AACE International Transactions, R9.1-R9.6
Bektas S, Birgonul MT, Dikmen I (2021) Integrated probabilistic delay analysis method to estimate expected outcome of construction delay disputes. Journal of Legal Affairs and Dispute Resolution in Engineering and Construction 13(1):1–18, DOI: https://doi.org/10.1061/(ASCE)LA.1943-4170.0000439
Braimah N (2013) Construction delay analysis techniques — A review of application issues and improvement needs. Buildings 3(3):506–531, DOI: https://doi.org/10.3390/buildings3030506
Braimah N, Ndekugri I (2007) Factors influencing the selection of delay analysis methodologies. International Journal of Project Management 26(8):789–799, DOI: https://doi.org/10.1016/j.ijproman.2007.09.001
Bramble BB, Callahan MT (2004) Construction delay claims. Taylor & Francis, Gaithersburg, MD, USA, 103–120
Bubshait AA, Cunningham MJ (1998) Comparison of delay analysis methodologies. Journal of Construction Engineering and Management 124(4):315–322, DOI: https://doi.org/10.1061/(ASCE)0733-9364(1998)124:4(315)
Budayan C, Dikmen I, Birgonul MT, Ghaziani A (2018) A computerized method for delay risk assessment based on fuzzy set theory using MS Project™. KSCE Journal of Civil Engineering 22(8):2714–2725, DOI: https://doi.org/10.1007/s12205-018-0810-3
Callahan MT, Quackenbush DG, Rowings JR (1992) Construction project scheduling. McGraw-Hill, New York, NY, USA, 86–210
D’Onofrio RM, Meagher AL (2013) What is a schedule good for? A study of issues posed by schedules on complex projects. The Constuction Lawyer 33:6
D’Onofrio R (2015) Ranking AACE international’s forensic schedule analysis methodologies. Cost Engineering 57(4):4–10
Dale WS, D’Onofrio RM (2014) Construction schedule delays. Thomson Reuters, Eagan, MN, USA, 75–132
Doǧan SZ, Arditi D, Günaydın HM (2006) Determining attribute weights in a CBR model for early cost prediction of structural systems. Journal of Construction Engineering and Management 132(10):1092–1098, DOI: https://doi.org/10.1061/(ASCE)0733-9364(2006)132:10(1092)
Kavuma A, Ock J, Jang H (2019) Factors influencing time and cost overruns on freeform construction projects. KSCE Journal of Civil Engineering 23(4):1442–1450, DOI: https://doi.org/10.1007/s12205-019-0447-x
Kim H, Soibelman L, Grobler F (2008) Factor selection for delay analysis using knowledge discovery in databases. Automation in Construction 17(5):550–560, DOI: https://doi.org/10.1016/j.autcon.2007.10.001
Kim SY, Tuan KN, Luu VT (2016) Delay factor analysis for hospital projects in Vietnam. KSCE Journal of Civil Engineering 20(2):519–529, DOI: https://doi.org/10.1007/s12205-015-0316-1
Koo B, Fischer M, Kunz J (2007) A formal identification and re-sequencing process for developing sequencing alternatives in CPM schedules. Automation in Construction 17(1):75–89, DOI: https://doi.org/10.1016/j.autcon.2007.03.005
Lai CC, Lee WL (2006) A WICE approach to real-time construction cost estimation. Automation in Construction 15(1):12–19, DOI: https://doi.org/10.1016/j.autcon.2005.01.005
Le-Hoai L, Lee YD, Lee JY (2008) Delay and cost overruns in Vietnam large construction projects: A comparison with other selected countries. KSCE Journal of Civil Engineering 12(6):367–377, DOI: https://doi.org/10.1007/s12205-008-0367-7
Morganti National, Inc. v. United States, 49 Fed. Cl. 110 (2001) US Court of Federal Claims, Retrieved April 26, 2021, http://www.uscfc.uscourts.gov/sites/default/files/opinions/Morganti.pdf
Motawa IA, Anumba CJ, Lee S, Peña-Mora F (2007) An integrated system for change management in construction. Automation in Construction 16(3):368–377, DOI: https://doi.org/10.1016/j.autcon.2006.07.005
Nelson R, Livengood J (2017) Mixed forensic schedule analysis methodologies — proceed with caution. Cost Engineering 59(6):4–9
Palaneeswaran E, Kumaraswamy MM (2008) An integrated decision support system for dealing with time extension entitlements, Automation in Construction 17(4):425–438, DOI: https://doi.org/10.1016/j.autcon.2007.08.002
Perera NA, Sutrisna M, Yiu TW (2016) Decision-making model for selecting the optimum method of delay analysis in construction projects. Journal of Management in Engineering 32(5):1–14, DOI: https://doi.org/10.1061/(ASCE)ME.1943-5479.0000441
Peters TF (2007) Performing forensic delay analyses from deep within the black tent. AACE International Transactions 11–19
Schumacher L (1995) Quantifying and apportioning delay on construction projects. Cost Engineering 37(2):11–13
Society of Construction Law (2017) Delay and disruption protocol, Society of Construction Law, Retrieved August 1, 2020, https://www.scl.org.uk/resources/delay-disruption-protocol
Stumpf GR (2000) Schedule delay analysis. Cost Engineering 42(7):32–43
Yang JB, Huang KM, Lee CH, Chiu CT (2014) Incorporating lost productivity calculation into delay analysis for construction projects. KSCE Journal of Civil Engineering 18(2):380–388, DOI: https://doi.org/10.1007/s12205-014-0128-8
Zack JG (2001) But-for schedules-analysis and defense. Cost Engineering 43(8):13–17
Zafar ZQ (1996) Construction project delay analysis. Cost Engineering 38(3):23–28
Acknowledgments
This work was supported by the National Research Foundation of Korea (NRF) grant funded by the Korea government (MSIT) [grant number NRF-2018R1A5A1025137] and close collaboration with Kyungpook National University (KNU), Daegu, Korea.
Author information
Authors and Affiliations
Corresponding author
Rights and permissions
About this article
Cite this article
Yang, J., Arditi, D., Lee, DE. et al. Delay Analysis Selection Model for a Construction Project. KSCE J Civ Eng 26, 4926–4941 (2022). https://doi.org/10.1007/s12205-022-2394-1
Received:
Accepted:
Published:
Issue Date:
DOI: https://doi.org/10.1007/s12205-022-2394-1