Abstract
Delay is a common problem of the construction sector and it is one of the major reasons of claims between project participants. Systematic and reliable delay analysis is critical for successful management of claims. In this study, a delay analysis ontology is proposed that may facilitate development of databases, information sharing as well as retrieval for delay analysis within construction companies. A detailed literature review on construction delays has been carried out during the development of the ontology and it is evaluated by using five case studies. The delay analysis ontology may be used for different purposes especially to support decision-making during risk and claim management processes. It may enable companies to create their own databases, corporate memories and develop decision support systems for better analysis of delays.
Similar content being viewed by others
References
Abdul-Malak, M. A. U., El-Saadi, M. M. H., and Abou-Zeid, M. G. (2002). “Process model for administrating construction claims.” Journal of Management in Engineering, Vol. 18, No. 2, pp. 84–94, DOI: 10.1061/(ASCE)0742-597X(2002)18:2(84).
Abdul-Rahman, H., Berawi, M. A., Berawi, A. R., Mohamed, O., Othman, M., and Yahya, I. A. (2006). “Delay mitigation in the Malaysian construction industry.” Journal of Construction Engineering and Management, Vol. 132, No. 2, pp. 125–133, DOI: 10.1061/(ASCE)0733-9364(2006)132:2(125).
Abdul-Rahman, H., Yahya, I. A., Berawi, M. A., and Wah, L. W. (2008). “Conceptual delay mitigation model using a project learning approach in practice.” Construction Management and Economics, Vol. 26, pp. 15–27, DOI: 10.1080/01446190701744350.
Aibinu, A. A. and Jagboro, G. O. (2002). “The effects of construction delays on project delivery in Nigerian construction industry.” International Journal of Project Management, Vol. 20, No. 8, pp. 593–599, DOI: 10.1016/S0263-7863(02)00028-5.
Alaghbari, W., Kadir, M. R. A., Salim, A., and Ernawati. (2007). “The significant factors causing delay of building construction projects in Malaysia.” Engineering, Construction and Architectural Management, Vol. 14, No. 2, pp. 192–206, DOI: 10.1108/09699980710731308.
Arditi, D. and Patel, B. K. (1989). “Impact analysis of owner-directed acceleration.” Journal of Construction Engineering and Management, Vol. 115, No. 1, pp. 144–157, DOI: 10.1061/(ASCE)0733-9364 (1989)115:1(144).
Arditi, D. and Pattanakitchamroon, T. (2006). “Selecting a delay analysis method in resolving construction claims.” International Journal of Project Management, Vol. 24, No. 2, pp. 145–155, DOI: 10.1016/j.ijproman.2005.08.005.
Arditi, R. D., Akan, G. T., and Gurdamar, S. (1985). “Reasons for delays in public projects in Turkey.” Construction Management and Economics, Vol. 3, No. 2, pp. 171–181, DOI: 10.1080/01446198500000013.
Besogul, E. (2006). Reasons of delays in steel construction projects: An application of a delay analysis methodology, M. S. Thesis, Middle East Technical University, Ankara, Turkey.
Bordoli, D. W. and Baldwin, A. N. (1998). “A methodology for assessing construction project delays.” Construction Management and Economics, Vol. 16, No. 3, pp. 327–337, DOI: 10.1080/014461998372358.
Breitman, K. K., Casanova, M. A., and Truszkowski, W. (2007). Semantic Web: Concepts, Technologies and Applications, Springer-Verlag London Limited, London, UK.
Bubshait, A. A. and Cunningham, M. J. (1998). “Comparison of delay analysis methodologies.” Journal of Construction Engineering and Management, Vol. 124, No. 4, pp. 315–322, DOI: 10.1061/(ASCE)0733-9364(1998)124:4(315).
Carnell, N. J. (2000). Causation and Delay in Construction Disputes, Blackwell Science Ltd., Oxford, UK.
Chandrasekaran, B., Josephson, J. R., and Benjamins, V. R. (1999). “What are ontologies, and why do we need them?.” IEEE Intelligent Systems, Vol. 14, No. 1, pp. 20–26, DOI: 10.1109/5254.747902.
Corcho, O., Fernández-López, M., and Gómez-Pérez, A. (2003). “Methodologies, tools and languages for building ontologies: Where is their meeting point?.” Data and Knowledge Engineering, Vol. 46, pp. 41–64, DOI: 10.1016/S0169-023X(02)00195-7.
Corcho, O., Fernández-López, M., Gómez-Pérez, A., and López-Cima, A. (2005). Building legal ontologies with METHONTOLOGY and WebODE. In R. Benjamins, P. Casanovas, J. Breuker, and A. Gangemi (Eds.), Law and the Semantic Web, Springer-Verlag Berlin Heidelberg, Germany.
Davenport, P. (1995). Construction Claims, Federation Press, Sydney, Australia.
Diekmann, J. E. and Girard, M. J. (1995). “Are contract disputes predictable?.” Journal of Construction Engineering and Management, Vol. 121, No. 4, pp. 355–363, DOI: 10.1061/(ASCE)0733-9364(1995)121:4(355).
El-Diraby, T. E. (2013). “Domain ontology for construction knowledge.” Journal of Construction Engineering and Management, Vol. 139, No. 7, pp. 768–784, DOI: 10.1061/(ASCE)CO.1943-7862.0000646.
El-Diraby, T. E. and Zhang, J. (2006). “A semantic framework to support corporate memory management in building construction.” Automation in Construction, Vol. 15, No. 4, pp. 504–521, DOI: 10.1016/j.autcon.2005.07.005.
El-Diraby, T. E. and Wang, B. (2005). E-Society Portal: Integrating urban highway construction projects into the knowledge city.” Journal of Construction Engineering and Management, Vol. 131, No. 11, pp. 1196–1211, DOI: 10.1061/(ASCE)0733-9364(2005)131:11(1196).
El-Gohary, N. M. and El-Diraby, T. E. (2011). “Merging architectural, engineering, and construction ontologies.” Journal of Computing in Civil Engineering, Vol. 25, No. 2, pp. 109–128, DOI: 10.1061/(ASCE)CP.1943-5487.0000048.
Farrow, T. (2007). “Developments in the analysis of extensions of time.” Journal of Professional Issues in Engineering Education and Practice, Vol. 133, No. 3, pp. 218–228, DOI: 10.1061/(ASCE)1052-3928(2007)133:3(218).
Fernandes, P. C. B., Guizzardi, R. S. S., and Guizzardi, G. (2011). “Using goal modeling to capture competency questions in ontology-based systems.” Journal of Information and Data Management, Vol. 2, No. 3, pp. 527–540.
Fidan, G., Dikmen, I., Tanyer, A. M., and Birgonul, M. T. (2011). “Ontology for relating risk and vulnerability with cost overrun in international projects.” Journal of Computing in Civil Engineering, Vol. 25, No. 4, pp. 1–16, DOI: 10.1061/(ASCE)CP.1943-5487.0000090.
Fox, M. S. and Grüninger, M. (1997). “On ontologies and enterprise modelling.” Proc. International Conference on Enterprise Integration and Modelling Technology, Torino, Italy.
Gómez-Pérez, A. (1996). “Towards a framework to verify knowledge sharing technology.” Expert Systems with Applications, Vol. 11, No. 4, pp. 519–529, DOI: 10.1016/S0957-4174(96)00067-X.
Gómez-Pérez, A. (2001). “Evaluation of ontologies.” International Journal of Intelligent Systems, Vol. 16, No. 3, pp. 391–409, DOI: 10.1002/1098-111X(200103)16:3<391::AID-INT1014>3.0.CO;2-2.
Gómez-Pérez, A., Fernández-López, M., and Corcho O. (2004). Ontological Engineering: with examples from the areas of knowledge management, e-commerce and the semantic web, Springer-Verlag London Limited, USA.
Gómez-Pérez, A., Fernández-López, M., and de Vicente, A. (1996). “Towards a method to conceptualize domain ontologies.” Proc. ECAI96 Workshop on Ontological Engineering, Budapest, Hungary, pp. 41–51.
Gruber, T. R. (1993a). “A translation approach to portable ontology specifications.” Knowledge Acquisition, Vol. 5, No. 2, pp. 199–220, DOI: 10.1006/knac.1993.1008.
Gruber, T. R. (1993b). “Toward principles for the design of ontologies used for knowledge sharing.” International Journal Human-Computer Studies, Vol. 43, Nos. 5-6, pp. 907–928, DOI: 10.1006/ijhc.1995.1081.
Gruninger, M. and Fox, M. S. (1994). “The role of competency questions in enterprise engineering1.” Proc. IFIP WG5.7 Workshop on Benchmarking -Theory and Practice, Trondheim, Norway.
Gruninger, M. and Fox, M. S. (1995). “Methodology for the design and evaluation of ontologies.” Proc. Workshop on Basic Ontological Issues in Knowledge Sharing, Montreal, Canada, DOI: 10.1.1.44.8723.
Ivanovic, M. and Budimac, Z. (2014). “An overview of ontologies and data resources in medical domains.” Expert Systems with Applications, Vol. 41, No. 11, pp. 5158–5166, DOI: 10.1016/j.eswa.2014.02.045.
Kartam, S. (1999). “Generic methodology for analyzing delay claims.” Journal of Construction Engineering and Management, Vol. 125, No. 6, pp. 409–419, DOI: 10.1061/(ASCE)0733-9364(1999)125:6(409).
Lee, C., Wang, H., and Chang, M. (2005a). “Ontology-based fuzzy decision agent and its application to meeting scheduling support system.” In S. K. Halgamuge and L. Wang (Eds.), Classification and Clustering for Knowledge Discovery, Springer-Verlag, Netherlands.
Lee, H.-S., Ryu, H.-G., Yu, J.-H., and Kim, J.-J. (2005b). “Method for calculating schedule delay considering lost productivity.” Journal of Construction Engineering and Management, Vol. 131, No. 11, pp. 1147–1154, DOI: 10.1061/(ASCE)0733-9364(2005)131:11(1147).
Lee, S., Kim, K., and Yu, J. (2015). “Ontological inference of work item based on BIM data.” KSCE Journal of Civil Engineering, Vol. 19, No. 3, pp. 538–549 DOI: 10.1007/s12205-013-0739-5.
Lima, C., El-Diraby, T., Fies, B., Zarli, A., and Ferneley, E. (2003). “The E-COGNOS project: Current status and future directions of an ontology-enabled IT solution infrastructure supporting knowledge management in construction.” Proc. Construction Research Congress 2003, Honolulu, Hawaii, United States, pp. 1–8, DOI: 10.1061/40671(2003)103.
Ndekugri, I., Braimah, N., and Gameson, R. (2008). “Delay analysis within construction contracting organizations.” Journal of Construction Engineering and Management, Vol. 134, No. 9, pp. 692–700, DOI: 10.1061/(ASCE)0733-9364(2008)134:9(692).
Neches, R., Fikes, R. E., Finin, T., Gruber, T. R., Senator, T., and Swartout, W. R. (1991). “Enabling technology for knowledge sharing.” AI Magazine, Vol. 12, No. 3, pp. 36–56, DOI: 10.1609/aimag.v12i3.902.
Niu, J. and Issa, R. R. A. (2012). “Framework for production of ontologybased construction claim documents.” Proc. International Conference on Computing in Civil Engineering, Clearwater Beach, Florida, United States, pp. 9–16, DOI: 10.1061/9780784412343.0002.
Noy, N. F. and McGuinness, D. L. (2001). “Ontology development 101 -a guide to creating your first ontology.” KSL Technical Report, Stanford University, Stanford, CA,USA.
Noy, N. F., Fergerson, R. W., and Musen, M. A. (2000). “The knowledge model of Protég-2000: Combining interoperability and flexibility.” Proc. 2nd International Conference on Knowledge Engineering and Knowledge Management, Juan-les-Pins, France, DOI: 10.1007/3-540-39967-4_2.
O’Brien, J. J. (1976). Construction Delay: Responsibilities, Risks, and Litigation, Cahners Books International, Boston.
Park, M., Lee, K.-W., Lee, H.-S., Jiayi, P., and Yu, J. (2013). “Ontologybased construction knowledge retrieval system.” KSCE Journal of Civil Engineering, Vol. 17, No. 7, pp. 1654–1663, DOI: 10.1007/s12205-013-1155-6.
Purchase, H. C., Colpoys, L., McGill, M., Carrington, D., and Britton, C. (2001). “UML class diagram syntax: An empirical study of comprehension.” Proc. Australian Symposium on Information Visualisation, Sydney, Australia, pp. 113–120.
Sambasivan, M. and Soon, Y. W. (2007). “Causes and effects of delays in Malaysian construction industry.” International Journal of Project Management, Vol. 25, No. 5, pp. 517–526, DOI: 10.1016/j.ijproman.2006.11.007.
Scott, S., Harris, R. A., and Greenwood, D. (2004). “Assessing the new United Kingdom Protocol for dealing with delay and disruption.” Journal of Professional Issues in Engineering Education and Practice, Vol. 130, No. 1, pp. 50–59, DOI: 10.1061/(ASCE)1052-3928(2004)130:1(50).
Suárez-Figueroa, M. C., Gómez-Pérez, A., and Villazón-Terrazas, B. (2009). “How to write and use the ontology requirements specification document.” Proc. ODBASE 2009 on the OTM 2009, Vilamoura, Algarve, Portugal, pp. 966–982, DOI: 10.1007/978-3-642-05151-7_16.
Sun, M. and Meng, X. (2009). “Taxonomy for change causes and effects in construction projects.” International Journal of Project Management, Vol. 27, No. 6, pp. 560–572, DOI: 10.1016/j.ijproman.2008.10.005.
Thomas, R. (1993). Construction Contract Claims, Macmillan Press Ltd., London.
Trauner, T. J., Manginelli, W. A., Lowe, J. S., Nagata, M. F., and Furniss, B. J. (2009). Construction Delays: Understanding them clearly, analyzing them correctly, Elsevier Inc., USA.
Tserng, H. P., Yin, S. Y. L., Dzeng, R. J., Wou, B., Tsai, M. D., and Chen, W. Y. (2009). “A study of ontology-based risk management framework of construction projects through project life cycle.” Automation in Construction, Vol. 18, No. 7, pp. 994–1008, DOI: 10.1016/j.autcon. 2009.05.005.
Turner, D. F. and Turner, A. (1999). Building Contract Claims and Disputes, Addison Wesley Longman Limited, Edinburgh Gate, Harlow, Essex, England.
Uschold, M. and King, M. (1995). “Towards a methodology for building ontologies.” Proc. IJCAI-95 Workshop on Basic Ontological Issues in Knowledge Sharing, Montreal, Quebec, Canada, DOI: 10.1.1.55.5357.
Wang, H. and Wang, S. (2016). “Application of ontology modularization to human-web interface design for knowledge sharing.” Expert Systems with Applications, Vol. 46, pp. 122–128, DOI: 10.1016/j.eswa.2015.10.027.
Williams, T. (2003). “Assessing extension of time delays on major projects.” International Journal of Project Management, Vol. 21, No. 1, pp. 19–26, DOI: 10.1016/S0263-7863(01)00060-6.
Winter, J., Bayfield, R., Brough, P., Caletka, A., Douglas, J., Johnson, P., Jordan, S., Nash, S., Pickavance, K., Pragnell, J., and Richards, D. (2002). Delay and Disruption Protocol, Society of Construction Law.
Yang, J.-B. and Kao, C.-H. (2012). “Critical path effect based delay analysis method for construction projects.” International Journal of Project Management, Vol. 30, No. 3, pp. 385–397, DOI: 10.1016/j.ijproman.2011.06.003.
Yogeswaran, K., Kumaraswamy, M. M., and Miller, D. R. A. (1998). “Claims for extensions of time in civil engineering projects.” Construction Management and Economics, Vol. 16, No. 3, pp. 283–293, DOI: 10.1080/014461998372312.
Zack, J. G. (2000). “Pacing delays -The practical effect.” Cost Engineering, Vol. 42, No. 7, pp. 23–28.
Zhou, Z., Goh, Y. M., and Shen, L. (2016). “Overview and analysis of ontology studies supporting development of the construction industry.” Journal of Computing in Civil Engineering, DOI: 10.1061/(ASCE)CP.1943-5487.0000594.
Author information
Authors and Affiliations
Corresponding author
Rights and permissions
About this article
Cite this article
Bilgin, G., Dikmen, I. & Birgonul, M.T. An ontology-based approach for delay analysis in construction. KSCE J Civ Eng 22, 384–398 (2018). https://doi.org/10.1007/s12205-017-0651-5
Received:
Revised:
Accepted:
Published:
Issue Date:
DOI: https://doi.org/10.1007/s12205-017-0651-5